Professional Negligence
Architect Dispute
Case Study
- 100% Confidential & No Obligation
PROFESSIONAL NEGLIGENCE DISPUTES
Professional negligence, the claimant sued his architect for failing to observe the correct planning permission granted for an extension to his public house. It was alleged that due to the architects incompetence delays occurred as well as the expenditure of putting his errors right alongside the loss of business accumulating in an action totalling £92,000.
PROFESSIONAL NEGLIGENCE DISPUTE SOLUTION
From the joint and separate meetings at the mediation it was quite clear the architect admitted he had made an error, and was willing to put this right; however the claim for £92,000 was excessive.
The public house had to delay their grand opening, it transpired due to various technical issues and complexities out of the control of the architect regardless of his error there would have still been delays.
The claimant did recall a brief conversation about this months ago, therefore with the delay in opening being inevitable the loss of business claim which made up the bulk of the claimants claim was not entirely accurate.
Several offers, counter offers were made, whereby the difference between the parties was £10,000, the parties split the difference and settled for £33,500.
PROFESSIONAL NEGLIGENCE DISPUTE STATISTICS
The mediation took 1 day compared to the 7 months this professional negligence dispute had already gone on.
The mediation cost each party, only a fraction each, compared to the thousands they had already spent on legal fees, and the thousands they would have had to spend, had they continued with Court action.
PROFESSIONAL NEGLIGENCE MEDIATION VIDEO
CLICK ON THE MEDIATORS
NAME TO VIEW THEIR WHOLE CV
2002 CEDR, Academy of Experts, ADR Group Accredited Mediator. 21+years of experience. 1000+ mediation’s, 90% success rate. Mediated every type of commercial, workplace, boundary & family dispute. CIArb mediation assessor & trainer since 2007. ADR Group, Head of Mediation Training 2018 – 2020. English & Punjabi speaker.
Harvinder Singh BhurjiLLB (Hons), QDR(M), MCIArb, MCMI, CTLLSDirector, International Commercial & Workplace Mediator & Trainer
1998 CEDR & ADR Group Accredited Mediator. 25 years experience, CIArb & RICS mediation trainer & assessor. Coach since 1987. Specialisms racial discrimination, unfair & constructive dismissal, bullying. Property, family businesses, construction, professional negligence. Director, partnerships, business, joint venture, debt, employment.
Jane WalmsleyBA, LLB, LLM, MCIArb, UKCP, MBACPPsychotherapist, Coach, Commercial &
Workplace Mediator, Barrister (non-practicing)
2004 ADR Group Accredited Mediator. 19 years mediation experience. CIArb Commercial Mediation Assessor. Solicitor & Consultant at Freeths 45+ years. Specialisms, dispute resolution, professional negligence, clinical negligence, product liability, personal injury, defamation & sports law.
Paul BalenLLB (Hons), Solicitor & Consultant at Freeths LLP, Director of Trust Mediation, Commercial Mediator
Dentist, CIArb & ADR Group Accredited Mediator, 18 years mediation experience, has been involved in over 100 civil & commercial mediations.
Dr. Michael ButterworthBDS, DGDP(UK), MFDS (RCS Eng), LLM, MCIArbDentist & Commercial & Family Mediator
2005 ADR Chambers Accredited Mediator. 18 years mediation experience. Chartered Accountant & Insurance Practitioner. Expert witness. Specialisms, insurance, liquidations, professional negligence, construction & boundaries.
David S BlackBSc (Hons) CA FCII FCILA ACIArb MEWICommercial Mediator & Accountant
2017 CEDR Accredited, 6 years mediation experience. Specialisms, commercial, company, contract, property, probate, IP & professional negligence.
Tim BennettPartner & Head of Dispute Resolutionat Bray & Bray Solicitors, 2007 - 2020.
CEDR Accredited Commercial Mediator
2005 CEDR Accredited Mediator, 18 years mediation experience. Proprietor of Beaumonde Law Practice, Solicitor & employment law specialist. Specialisms company, unfair dismissal, discrimination & compromise agreements. English & Punjabi speaker.
Sundeep Singh BhatiaEmployment Solicitor & Commercial Mediator 
2011 CIArb Accredited Mediator. 12 Years Mediation Experience. 400+ mediations.
CIArb Mediation Assessor. Specialisms, construction, property, commercial, boundaries, probate & professional negligence.
Bruce BourneMRICS, MCIArb, Chartered Surveyor, Commercial Mediator 
2009 RICS Accredited Mediator. 14 years mediation experience. Fellow of the Royal Institution of Chartered Surveyors.
Expert Witness, Determination. Specialisms construction, dilapidations, property & boundary.
Richard CavadinoChartered Quantity Surveyor & Commercial Mediator 
2010 CIArb Accredited Mediator. 13 years mediation experience. Specialisms, construction, engineering, contract, employment, partnership, shareholder & professional negligence disputes.
Martin CollingwoodSolicitor, Commercial Mediator,Arbitrator, Adjudicator, Med – Arb specialist
2004 CEDR & ADR Group Accredited Mediator. 19 years mediation experience. Barrister,
conducted 110+ mediations. Specialisms, boundary, landlord & tenant, employment, contractual disputes.
David DalyBarrister & Commercial Mediator 
1996 CIArb Accredited mediator. 27 years mediation experience. Qualified as a solicitor in 1962. Specialisms. all forms of building and civil engineering projects in the UK & overseas.
Roderick O'DriscollFCIArb, MBEng, Chartered Arbitrator, Accredited Mediator,Notary Public, Qualified Solicitor of the Supreme Court
1998 Academy of Experts Accredited Mediator. Qualified Dispute Resolver. 25 years mediation experience. CIArb commercial mediation course tutor & assessor. Issued well over 400 awards, decisions in civil & commercial disputes. Specialisms all commercial matters.
Ike EhiribeLLB (Hons) lagos, B.L, FCIArb, FSIArb, QDR, Barrister, Chartered Arbitrator, Adjudicator, Visiting Professor & Commercial Mediator
2003 CEDR Accredited Mediator. 20 years mediation experience. Manchester University lecturer, visiting lecturer & professor at several overseas universities. CIArb commercial mediation course tutor & assessor. Specialisms construction & engineering.
Dr. Peter FennBSc PhD FRICS FCIArb, Academic, Quantity Surveyor,Adjudicator, Arbitrator & Commercial Mediator
1996 CEDR Accredited Mediator. 27 years mediation experience. CIArb commercial mediation course tutor & assessor. Specialisms, construction, contracts, corporate sale, landlord & tenant, employment, personal injury & professional negligence.
Grant GoodladBarrister & Commercial Mediator
2002 CEDR Accredited Mediator. 21 years mediation experience. Consensio workplace mediation course trainer. Specialisms, business, charities, contract, education, workplace, landlord & tenant, media, partnership, public sector, wills & probate.
Carolyn GrahamCommercial & Workplace Mediator 
ADR Group Accredited Mediator. 17 years mediation experience. 19 years as a civil litigator. Specialisms, personal injury, clinical & professional negligence, partnership, employment, landlord & tenant, commercial contract, boundary & probate disputes.
Phil HeskethSolicitor till 2008, Commercial Mediator
1997 ADR Group Accredited Mediator. 26 years mediation experience. Head of insurance litigation department, specialising in personal injury & insurance litigation. Specialisms, personal injury, professional negligence, partnership, landlord & tenant.
Paul Hughes Solicitor & Commercial Mediator 
2007 ADR Group Accredited Mediator.16 years mediation experience. Specialisms, property, insurance, construction, professional negligence, boundaries, landlord & tenant & engineering.
Russell JonesSolicitor & Commercial Mediator 
2008 Accredited Mediator. 15 years mediation experience. Specialisms, commercial, company, contract, employment, insolvency & personal injury law.
Joe Al KhayatBarrister & Commercial Mediator 
2003 CEDR Accredited Mediator. 2004 ADR Group Accredited Mediator. 20 years mediation experience. Various directorships. Specialisms, building, construction, family business, partnership, commercial contracts, landlord & tenant & professional negligence.
Robin LeaBSc Mech Engineering, Commercial Mediator
1999 CEDR Accredited Mediator. 90% success rate. 24 years mediation experience. Specialisms, contract, employment, boundary, building & construction.
Edward LegardBarrister, Employment Judge & Commercial Mediator 
2007 ADR Group Accredited Mediator. 16 years mediation experience. Specialisms, construction, property, commercial landlord & tenant, boundary, shared ownership, occupation & Inheritance Act disputes.
Michael McCourtLLB MSc FCIArb, Deputy DistrictJudge, Commercial & Family Mediator
2001 ADR Group Accredited Mediator. 22 years mediation experience. Specialisms, building, construction, civil engineering, professional negligence, boundary & contracts.
Paul NewmanBarrister, Adjudicator & Commercial Mediator 
2002 ADR Group Accredited Mediator. 21 years mediation experience. Qualified as a Solicitor in 1982. Family Mediator (MIAMs) trained also. Specialisms, family, probate, contract, debt recovery, & workplace disputes.
Frances PlaceCommercial & Family Mediator 
1997 ADR Group Accredited Mediator. 26 years mediation experience. Solicitor since 1991, for many years having obtained a Ist Class Honours Law Degree from Liverpool University. Specialisms, commercial, company, contract, employment, insolvency & personal injury law.
John RocheLLB (Hons) Solcitor & Commercial Mediator
2007 ADR Group Accredited Mediator. 16 years mediation experience. Family & workplace mediation trained. Specialisms, probate, landlord / tenant, boundary, partnership, building, contract, insurance, professional negligence, family & workplace.
Julian RendallLLM, MCIArb, FMCA, MIAM's PPCSupervisor, Commercial, Workplace & Family Mediator
2002 CEDR Accredited Mediator. 21 years mediation experience. Specialisms, business, company, contract, debt recovery, director & partnerships.
Jeffrey C RosenthalBSc (Econ) FCCA FCIArb MAE, Accountant,Arbitrator, Expert Witness & Commercial Mediator
2008 ADR Group Accredited Mediator. 15 years mediation experience. Was a solicitor for 9 years, before being called to the Bar. Specialisms, litigation, trusts of land, property, landlord tenant & unlawful eviction.
Tom RussellBarrister & Commercial Mediator 
2008 ADR Chambers Accredited Mediator. 15 years mediation experience. Director at Davisons Solicitors & Head of the Dispute Resolution Team. Specialisms, construction, probate, family, employment, contract & professional negligence.
Umran SadiqSolicitor & Commercial Mediator 
2007 CIArb Accredited Mediator. 16 years mediation experience. Senior Counsel, Arbitrator, Conciliator, Med Arb & Expert Determination specialist. Specialisms, building, construction, civil engineering, rail, marine, energy, site remediation, professional negligence, contract & partnerships.
Ken SalmonMCIArb, Consultant Solicitor & Commercial Mediator 
2005 CEDR Accredited Mediator. 18 years mediation experience. Family Mediator also.
Vice President of the Law Society of England & Wales. English, Punjabi & Urdu speaker. Specialisms, property, boundary, directors, probate & contract.
Lubna ShujaSolicitor, Commercial & Family Mediator 
2003 ADR Group Accredited Mediator. 20 years mediation experience. 70+ mediations.
Specialisms, workplace, insurance, professional negligence, contract, property & private equity.
Louisa TaylorSolicitor & Commercial Mediator 
2002 CEDR Accredited Mediator. 21 years mediation experience. CIArb commercial mediation assessor. Issued over 175 arbitration awards. Co-author of ‘The Arbitration Act 1996 – A Commentary’. Principal Lecturer, University of the West of England. Specialisms, property, commercial & construction.
Jonathan TecksMA, FCIArb, DiplCArb, Barrister,Arbitrator, Academic & Commercial Mediator
2004 CEDR Accredited Mediator. 19 years mediation experience. Specialisms, construction, property, commercial, IT, market/industry analysis & business cases.
Dr Paul WheatlyCommercial Mediator
2003 ADR Chambers Accredited Mediator. 20 years experience. Family & workplace mediation trained. Specialisms, construction, engineering, PFI/Projects, professional negligence, neighbour, litigation, family & workplace.
Peter WebsterSolicitor, Commercial, Workplace & Family Mediator 
2019 Accredited Mediator. 4 Years Mediation Experience. Managing Partner Gotelee LLP. Employment Solicitor, specialisms, workplace,
employment & commercial litigation.
Andrew WestSolicitor, Commercial & Workplace Mediator 
20 Years of Experience, 1000+ Mediations, 90% success rate, mediated every type of commercial & workplace dispute.
Harvinder Singh Bhurji
Jane encourages people to take full advantage of the mediation process and the control...
Jane Walmsley
Dispute resolution; Professional negligence including Clinical Negligence; Product Liability; personal injury...
Paul Balen
Conduct of employment law matters including unfair dismissal, discrimination and compromise agreement.
Sundeep Singh Bhatia
Grants background involves both commercial and contentious aspects of the law.
Grant Goodlad
She works cross sector and has mediated a wide range of disputes especially employment and workplace.
Carolyn Graham
Professional Mediator accredited by ADR Group in 2006 with 19 years experience as a civil litigation solicitor
Phil Hesketh
Specialist employment practitioner covering all major aspects of employment law.
Edward Legard
Founded and managed Family Mediation Department at Lyons Davidson for 11 years.
Frances Place
Louisa is an experienced and highly competent mediator with a background in private equity.
Louisa Taylor
Construction & Engineering, PFI/Projects, Professional Negligence, Neighbour Disputes, Commercial Litigation..
Peter Webster
One of the UK’s most experienced commercial and workplace mediators and mediation trainers. Mediating since 2002 across all sectors with over 2000 mediation’s conducted.
Here to help you resolve your dispute quickly, cost effectively and without stress. As well as to answer all your questions about mediation.
Has mediated every single type of civil, commercial, employment, family, boundary, neighbour and workplace dispute. It is easier to say what he has not mediated, rather than what he has.
A Fellow of the Civil Mediation Council. A Law graduate, a CEDR, Academy of Experts & ADR Group Accredited Commercial Mediator. A Qualified Dispute Resolver, a UK Mediation Accredited Workplace & Community Mediator. A Qualified Manager through the Chartered Management Institute – Level 5.
An associate Teacher and qualified Trainer, holding the Certificate in Teaching in the Lifelong Learning Sector – Level 4. Since 2007 he has been on the global mediation training faculty of the Chartered Institute of Arbitrators. Who he has delivered mediation training for, in the UK and overseas, on numerous occasions. Between 2018 and 2020, he was the Head of Mediation Training for the ADR Group. The oldest (1989) mediation training provider in the UK.
